Posts

A Downer of a decision: The importance of articulating adjudication submissions

In Diona Pty Ltd v Downer EDI Works Pty Ltd [2020] NSWSC 480 (Diona), the Supreme Court considered an application to set aside an Adjudicator’s Determination for failure to consider the terms of the contract as required by s 22(2)(b) of the Building and Construction Industry Security of Payment Act 1999 (the SOP Act).

Key takeaway:

  • It is important to ensure that adjudication submissions clearly articulate all relevant arguments and contractual provisions. Unclear, poorly framed or ambiguous submissions can be costly.
  • An adjudicator’s decision will not be declared void simply because it contains what one party considers to be an error or failure by the adjudicator to expressly address all arguments made in parties’ submissions.
  • Lawyers can be useful to assist in preparing an adjudication application and response. Having prepared and responded to numerous security of payment claims, the lawyers at Bradbury Legal are experts at ensuring your arguments are clearly articulated.

 

Background

Diona Pty Ltd (Diona) entered into a subcontract with Downer EDI Works Pty Ltd (Downer), for Downer to provide works in relation to safety upgrades on the Great Western Highway, Blackheath. Downer proceeded to adjudication on a payment claim under the SOP Act. On 16 April 2020, the relevant Adjudicator determined that Downer was entitled to a progress payment of $430,990.13 (Determination).

Diona made an application to the Supreme Court, seeking a declaration that the Determination was void and an injunction preventing Downer from requesting an adjudication certificate or filing the adjudication certificate as a judgment debt. Diona contended that the Adjudicator had incorrectly awarded a set off claim by Downer, in response to Diona’s liquidated damages claim, in the amount of $30,000 on account of two extension of time claims (EOT Claims).

Diona argued that the Adjudicator had not fulfilled the requirements of s 22(2)(b) of the SOP Act because the Adjudicator had failed to give any reference to, or consideration of, Diona’s contention in its adjudication response submissions that Downer was not entitled to these extensions of time, due to the operation of a time bar in the contract.

 

Did the Adjudicator consider the time bars?

The central question was whether the Adjudicator considered the provisions of the contract. Under section 22(2)(b) SOP Act, an adjudicator must consider the provisions of the construction contract.

To determine if the Adjudicator did consider the contractual provisions, especially those containing the time bar, the Court looked at the submissions made by both parties and the Adjudicator’s determination.

The Court noted that Downer had ‘devoted a number of pages to its contentions concerning extension of time and, in particular, its asserted entitlement to EOT 18 and EOT 21’. This was contrasted with Diona’s submissions, the Court found did not properly engage with Downer’s EOT Claims. Diona’s submissions stated:

Determinations of claims for…extension of time…by Diona are final and cannot be disturbed except by raising a Claim under the Contract, see relevant clauses of the Subcontract.’

The Court highlighted a part of the Adjudicator’s reasons which stated:

The Act at section 22(2)(b) requires the adjudicator to consider the provisions of the construction contract when making the determination

Having regard to the Adjudicator’s express reference to s 22(2)(b) of the SOP Act, the Court stated that there were several reasons why the Adjudicator did not refer to the dispute clause in the Determination. Firstly, the Adjudicator may have felt that Diona did not properly articulate and develop the time bar argument. Alternatively, the Adjudicator may have misunderstood the submissions. The Court concluded that:

The Adjudicator may have come to the wrong decision about Dower’s entitlement to EOT 18 and EOT 21. But that, without more, is not a basis to set aside the set aside the determination.

The argument that Diona sought to raise, while potentially valid, was not properly articulated. Therefore, it could not be inferred that the Adjudicator had failed to consider the provisions of the subcontract as required by s 22(2)(b) of the SOP Act.

 

So what?

The significance of this case is that it shows that what appear to be errors or failures to consider an argument by an adjudicator will not always result in a basis to set aside the adjudicator’s determination. The adjudicator’s decision can be rough and ready, provided the adjudicator makes their decision in accordance with the SOP Act. Payments made under SOP Act are on account only and may be determined on a final basis at a later stage.

 

ADR Processes Part II

This article is Part II of our article on ADR process. In this article, we will be covering the common pitfalls of ADR clauses. In Part I, we discussed the different types of ADR processes that are common in construction law matters. You can find Part I of our article HERE. While there are benefits to ADR processes, the drafting of dispute resolution clauses can sometimes result in the clause being void and unenforceable. Alternatively, there are times where the drafting of the dispute resolution clause means parties are left with a result under the contract which is unfair or unjust in the relevant circumstances. Often dispute resolution clauses are thrown into a contract without the parties giving much thought or consideration as to its enforceability or suitability to the circumstances. The following matters are pitfalls you should consider when you are drafting a dispute resolution clause.

 

Factors that may make the clause void and unenforceable:

 

Precondition to Court or other legal action

 

One of the biggest problems with ADR clauses arises when they set compliance with the ADR process as a pre-condition to seeking any court relief. This is problematic because it attempts to prevent the parties from approaching the Court when it has jurisdiction. If not properly drafted, these types of clauses can make the dispute resolution term unenforceable.

 

Words or phrases to look out for:

 

The parties must not seek any court orders until the parties have attended mediation.

 

Words or phrases that can prevent the clause being unenforceable:

 

Nothing in this clause X prevents the parties from seeking urgent or injunctive relief from the Court.

 

The key difference between these clauses is that the first tries to remove the jurisdiction of the Court by preventing the parties from seeking any relief from the Court until after the ADR processes have been complied with. This can result in some of the parties’ legal rights being wrongly enforced under the contract. For example, in cases where one party seeks to have recourse to security and the other party disputes this, the ADR process mechanisms may be too slow in resolving this dispute. Therefore, it is appropriate for the Court to be able to order urgent or injunctive relief to prevent recourse to the security. The parties can still have the underlying dispute proceed to the elected ADR process, but the security providing party may be able to (in the interim) prevent recourse where it is contested that the other party is not entitled to the benefit of that security.

 

Agreement to agree

 

A dispute resolution clause will be unenforceable if it is void for uncertainty. This often happens when there is an agreement to agree in a clause. For example, if a contract provides that the parties must agree on a matter and the parties are unable to reach an agreement, where do the parties stand in respect of their contractual duties? In the context of a dispute resolution clause, this can occur when the parties are required to agree on the form of the dispute process, or the appropriate body to determine the dispute or the rules that are to be applied to determine the dispute.

 

Words or phrases to look out for:

 

The parties must agree on an expert’ or ‘the parties must agree on the form of dispute process

 

Words or phrases that can prevent the clause being unenforceable:

 

The parties must agree on an expert. If the parties cannot agree, the expert shall be appointed or administered by the [for example] Australian Disputes Centre.’

 

The important difference between the two clauses is the second has a mechanism for resolving the uncertainty. If the parties cannot agree on which expert should be appointed, the clause provides for a third party to appoint or determine who the expert will be. Obviously, when nominating a third party to make the decision, it is important to confirm that the third party can and will appoint a dispute resolution professional.

 

Time frames should also be included as part of these clauses to avoid uncertainty. For example, a clause may state that parties are given 14 days to meet together to discuss the dispute before it proceeds to mediation. Without the 14 day timeframe, there is no clear indicator of when the parties are to engage in their dispute resolution process. A deeming mechanism should also be included to account for when the parties simply do not comply with the dispute resolution process. For instance, if the parties do not meet within 14 days, then the dispute should be automatically referred to mediation, or expert determination (as per the next tier of the agreed dispute resolution process) or simply allowed to proceed to litigation.

 

Broad and unclear drafting

 

The last pitfall of dispute resolution clauses discussed in this article is broad and/or unclear drafting. As a general problem with contracts, broad and/or unclear drafting can result in less certainty in the obligations between the parties. In the context of a dispute resolution clause, unclear drafting may occur in any of the following circumstances:

 

  • where there is not a clear process for a dispute to be resolved;
  • where the scope of the ADR powers and what can they determine is not defined;
  • where the rules that guide the ADR process are not clearly referenced; and
  • when can parties appeal the decision.

 

The consequence of broad and/or unclear drafting is that when a dispute arises, further disputes may occur when it comes time to interpret the clause. If a Court considers that the clause is uncertain and is unable to be properly interpreted, it may be held that the clause is void for uncertainty.

 

To assist with some of the considerations that arise with broad or unclear drafting, the next section of this article gives commentary on some of the considerations of ADR clauses so as to ensure your clause is suited to the parties and properly drafted.

 

Important Considerations in ADR clauses

 

Scope of ADR power

 

A dispute resolution clause can be customised by the parties. One way that parties can customise their dispute resolution clause is by determining what types of dispute will be resolved in which ways. For example, the parties may agree that technical matters to do with the scope of works or variations are unsuited to a determination by a legal professional. In such technical matters, the Courts will often have to consider expert reports from both parties, including any updates and responses from the experts. Even after considering the expert reports, the Court may nevertheless be unequipped or unsuitable to determine exactly what the correct outcome is or should be. Methods such as expert appraisal or expert determination can be effective ways of the parties reducing their costs and ensuring an appropriate resolution of the dispute. If this method is agreed by the parties, it is important to clearly set out exactly which disputes are to be resolved in which way. For example, the dispute resolution clause may state that any dispute involving a disputed variation or defective work that hinges on a technical interpretation must be resolved through expert determination. Accordingly, such a clause would also express that any dispute that hinges on legal interpretation be directed to a court of competent jurisdiction.

 

Statutory Provisions

 

When drafting a dispute resolution clause, it is important to consider whether there are any statutory provisions that may impact on the operation of the clause. For example, the Home Building Act 1989 (NSW) prevents the use of arbitration in some contracts for residential building work. In Victoria, the Building and Construction Industry Security of Payment Act 2002 (VIC) has an intricate regime for claimable variations in high value contracts (being contracts with a consideration over $5,000,000). These statutory provisions can have significant impacts on the clauses chosen by the parties. Further, while the Home Building Act prohibits the use of arbitration, the Victorian Security of Payment Act has consequences for the parties depending on the type of resolution used. It is important then to consider the statutory provisions and what their effects may be.

 

Binding or non-binding

 

A major consideration that parties should think about is whether to have the dispute resolution process as a binding or non-binding method. The Courts have generally held that where parties agree to a binding dispute resolution process, they will be unable to appeal the determination. While there may be circumstances where the parties can appeal to have the determination overturned, as a general rule, parties should expect to be bound by the decision. Therefore, parties should consider when they want to be bound by the decision of the dispute resolution professional.

 

Rights of appeal

 

While the process may be binding, the parties may agree to allow for appeal rights in the dispute resolution clause. For example, the parties may agree that a decision can be appealed where a party claims there has been a manifest error of law or where the amount in dispute exceeds a specified threshold. These mechanisms are interesting ways that parties can customise their dispute process and ensure that they are satisfied with the way any potential disputes will play out. It is important to consider any cost implications with appeal rights. While parties may not wish to be bound by a decision in certain circumstances, appeal rights may inevitably lead to higher costs in resolving a dispute.

 

 

Corona virus and force majeure in construction contracts: Has your contract been immunised

While many were recovering from New Years’ celebrations, corona virus was starting to make its way into the headlines. For the last 2 months, corona virus has dominated the news with many people and businesses starting to feel its impact as borders are shut down and quarantines are imposed. At the time of writing, the World Health Organisation has reported that corona virus has spread to many parts of the world including Australia, North America and parts of Europe. With much of the corona outbreak concentrated to China, several businesses are starting to feel the economic impact. As the manufacturing hub of the world, China is responsible for much of the world’s imports. Further, as the corona virus spreads and causes further border shutdowns, it becomes harder for businesses to have certainty in knowing when they will be able to import or export their goods. With businesses having to meet their contractual deadlines, the uncertainty can create a real issue for some. Consequently, many businesses may be put into a position where they are unable perform their contractual obligations. This article focuses on the different ways a construction contract may deal with situations such as corona virus.

The clause typically suited to situations or events like the outbreak of corona virus is a force majeure clause. Force majeure means ‘superior force’ and commonly covers natural events such as earthquakes or unforeseeable and disruptive manmade events such as war and industrial strikes. In the Australian context, force majeure clauses are creatures of the contract. This means that they only exist by virtue of a contractual provision which allocates the risk between the parties. Further, Australian courts will interpret these clauses strictly, giving the clauses the minimum application available within the ordinary meaning of the provision. In the construction contract context, it is unusual to see a specific force majeure clause. By way of illustration, the Australian Standard contracts do not contain a standard force majeure clause. Therefore, it is up to the parties to amend and insert a specific force majeure provision into the contract if they wish to have a specific mechanism dealing with the risk arising from these types of events.

As many readers may be aware, at the core of construction contracts is the allocation of risk through program. Therefore, construction contracts may, by their very essence, be differentiated from non—construction contracts. For example, extension of time (EOT), delay costs and liquidated damages clauses assign time related risks between the parties. The definitions of qualifying causes of delay and compensable causes in the Australian Standard provide a mechanism to pass time and cost related risks from contractors or subcontractors to the developer or head contractor. Amending the definition of qualifying causes of delay to extend to force majeure events is one way a construction contract can account for circumstances such as the corona virus. The key difference between allowing relief through a force majeure clause and allowing an EOT for force majeure events is that an EOT provides a contractor or subcontractor protection against liquidated damages. This is differentiated from a force majeure clause which may generally limit a party’s liability under the contract.

Irrespective of the way force majeure events are incorporated into construction contracts, care must be taken in drafting these clauses. When getting into the force majeure territory, contractors and subcontractors need to make sure that the definition of ‘force majeure’ or ‘force majeure event’ is drafted clearly, but not too broadly. For example, stating that a subcontractor is entitled to an EOT for anything outside of their control may be clear, but too broad to specifically cover corona virus. However, stating that the subcontractor is entitled to an EOT for delays related to the corona virus may be clearly drafted, but it does not provide much further scope. The clause would not protect from outbreaks or re-emergence of SARS or other endemics, epidemics or pandemics. A balance must be reached between these two extremes and will depend on the specific project.

When drafting a force majeure clause, it is important to consider some broad points. Firstly, force majeure clauses are usually exhaustive in nature, meaning that only what is in the contract is covered. Secondly, the party affected by the force majeure event must not have caused or contributed to the event and will required to take all steps to overcome or mitigate its effects. There also needs to be a connection between the force majeure event and the performance of the contractual obligations. For instance, the mere occurrence of the corona virus is not sufficient to justify an EOT in all cases. It will only entitle relief from liquidated damages when the event has caused a delay. By including these conditions, a force majeure clause (whether in EOT form or specific clause form) will generally entitle a party to relief or suspension of their obligations under the contract.

A significant problem with force majeure events is that it can be difficult for parties to establish that they should be entitled to relief under the clause. For example, in relation to the mitigation element discussed above, a party is often required to show that it cannot fulfil its supply obligations. While a party may have its preferred third party supplier, the mere fact that supply is not available from this supplier will not justify force majeure relief. The parties are bound by their contractual deal and this remains the case even if the obligations become significantly more onerous or expensive to complete. However, if all of the supply of product X is unavailable, then a party should be entitled to relief under the relevant clause until the supply becomes available again.

If you or someone you may know is in need of advice on existing contracts or advice regarding the force majeure clause, please contact our office by phoning (02) 9248 3450 or by email at info@bradburylegal.com.au.

What’s in a name?: The Supreme Court Reviews ambiguity in SoPA Payment Claims

Those who are familiar with the Building and Construction Industry Security of Payment Act 1999 (‘the Act’) will likely be aware that the provisions it contains are quite strict, and can leave parties out in the cold when they fail to comply with what are seemingly administrative oversights.

However, the overarching purpose of the Act is ultimately to keep money flowing through the construction system, aimed at ensuring those who perform building and construction works, or supply goods and services to construction projects are able to be paid.

The Supreme Court of New South Wales, in the recent decision of decision Modog Pty Ltd v ZS Constructions (Queenscliff) Pty Ltd [2019] NSWSC 1743 reminded parties of this fact when asked to turn its mind to issues of ambiguity in payment claims and whether a party could be allowed to have an adjudication determination quashed on the basis of technicalities.

The Facts

The facts of the case were reasonably clear and did not form a substantial component of the dispute between the parties. In September 2016, Modog Pty Ltd (‘Modog’) entered into a design and construct head contract with Wyndora 36 Pty Ltd (‘Wyndora’) for the development of senior living apartments at a property located along Wyndora Avenue in Freshwater. Modog then entered a sub-contract with ZS Constructions (Queenscliff) Pty Limited (ZS Queenscliff) for the demolition of the existing structure and the construction of the new seniors living complex, including apartments, basement parking and associated site works (‘the Sub-Contract’).

In March 2018, the Sub-contract was varied to engage ZS Queenscliff to provide Construction Management and procurement services, for which ZS Queenscliff would receive a project manager’s allowance, a contract administrator’s allowance and payments for subcontractors and suppliers to be made at the end of each month.

ZS Queenscliff was part of a wider group of entities, which also included ZS Constructions (Australia) Pty Ltd (‘ZS Australia’) and Zaarour Investments Pty Ltd had been engaged as the project manager for the project. Mr Christopher Zaarour was employed by ZS Queenscliff, was the director of ZS Constructions Pty Ltd and was the primary contact with Modog for the duration of the project.

The further sub-contracts on the project were administered by ZS Queenscliff, however invoices from sub-contractors had historically been issued to a mixture of Modog, Wyndora and ZS Australia, as opposed to ZS Queenscliff. During the course of the project, ZS Queenscliff and Modog adopted a progress payments process in which Mr Zaarour would, on behalf of ZS Queenscliff, prepare and email a payment summary sheet listing all amounts due for procurement and management services, as well as materials acquired, and work completed by trade contractors.

On 29 August 2019, Modog issued a Show Cause Notice to ZS Queenscliff and terminated the Sub-contract on 13 September 2019.

The Payment Claim and Adjudication

On 11 September 2019, ZS Queenscliff served a payment claim on Modog which was comprised of seven emails, from Mr Zaarour using an email signature from Zaarour Sleiman and containing a reference to ZS Australia in fine print at the bottom of the email.

The emails attached supporting invoices from suppliers, and followed the process adopted in earlier progress payments, where sub-contractors and suppliers had addressed their invoices to a mixture of the entities involved with the project, and not to ZS Queenscliff, who were issuing the payment claim.

The payment claim served on Modog was, as highlighted by the Court, unclear in the following respects:

  • It did not specifically assert that it was a progress payment claim under the Act;
  • It did not specify the reference date or refer to the clause within the contract upon which the progress payment was based;
  • It failed to ask Modog to pay ZS Queenscliff;
  • It did not include a total for the sum claimed, only determinable by a thorough review of the claims

Modog, in turn responded to the payment claim with payment schedules which certified the amount payable in respect of the Claim was nil.

The matter proceeded to an adjudication, where, on 23 October 2019, the adjudicator found in favour of ZS Queenscliff in the sum of $89,111.89 (GST incl.).

Modog challenged the decision of the adjudicator before the Supreme Court of Sydney, seeking orders that the Adjudication Determination of be deemed void, that the determination be quashed, and ancillary relief.

The Disputed Issues

At the hearing, Modog challenged the decision of the adjudicator on 3 primary grounds:

  • Whether the 11 September 2019 emails constituted a payment claim within the meaning of s13(1) of the Act;
  • If the emails did constitute a payment claim, whether the claim was sent by ZS Queenscliff as a person who was entitled to seek a determination for the purposes of s17 of the Act; and
  • Whether the Adjudicator has committed a jurisdictional error by allowing multiple payment claims in respect of a single reference date?

The Arguments, Decision and Reasoning

Issue 1: Was there a Payment Claim:

The argument advanced by Modog was effectively, ZS Queenscliff had not submitted a valid payment claim as they did not specifically demand payment from Modog (i.e.: did not say, Modog must pay ZS Queenscliff the sum of $X.). Modog relied on the fact that the invoices provided in support of the payment claim, were addressed to various entities, not ZS Queenscliff, and that ZS Queenscliff could not establish they were actually entitled to the money claimed for.

Modog argued that ZS Queenscliff had indicated invoices would be sent at a later time, which Modog was to pay as directed and that, pursuant to the Court’s decision in Quickway Constructions Pty Ltd v Electrical Energy Pty Ltd, ZS Queenscliff had not served a payment claim pursuant to clause 13(1) of the Act.

The counter argument raised by ZS Queenscliff relied upon the case of Icon Co NSW Pty Ltd v Australia Avenue Developments Pty Ltd [2018] to support their position that Modog had simply misunderstood the payment claim, and that this could not be a basis for quashing the adjudicator’s decision. ZS Queenscliff argued the fact that the invoices were addressed to other parties did not invalidate the payment claim as they were simply disbursements to be paid to suppliers.

Ultimately, the Court favoured the position raised by ZS Queenscliff, noting there is nothing within the Act that requires a payment claim to state the total of the sum claimed. The Court stated and that even if the invoices in support of the payment did require Modog to direct payment elsewhere, as long as ZS Queenscliff had an entitlement to the sum under the contract, this did not invalidate the payment claim itself.

Issue 2: Was the Payment Claim Sent by ZS Queenscliff?

Modog then raised the issue that, as the 11 September 2019 email enclosing the payment claim was sent by Mr. Zaarour, using an email signature that did not belong to ZS Queenscliff, and the only legal entity named in the email was ZS Australia, the payment claim had not been served by the appropriate entity for the purposes of s17 of the Act.

The counter argument raised by ZS Queenscliff was that these errors were irrelevant in light of the fact that the previous correspondence between the parties had been exchanged in much the same way, including when detailing the terms of the caries contract agreements, and the point was not taken at the contract negotiation stage.

The Court ultimately agreed again with ZS Queenscliff, making the point that not was not actually disputed that ZS Queenscliff was entitled to make the payment claim and made the determination that the email payment claim had simply been sent by Mr Zaarrour in his capacity as the project manager, on behalf of ZS Queenscliff.

Issue 3: Was there an issue with multiple emails being used to comprise the payment claim?

Finally, Modog sought to raise the point that multiple invoices had been served on them in the emails from ZS Queenscliff and that it was not open for ZS Queenscliff to seek to have all invoices adjudicated.

Relying on the decision of the court in Rail Corporations of NSW v Nebax Constructions [2012] NSWSC6, this point ultimately failed as well, on the basis that, when viewed in the context of the previous conduct between the parties, and the nature of the invoices supplied, Modog had been more accurately provided with one payment claim, and a number of invoices in support of the claim.

What does this decision mean?

This decision serves as a timely reminder to parties that the Building and Construction Industry Security of Payment Act 1999 (‘the Act’) is intended to allow money to flow through to sub-contractors. Parties should be mindful of this purpose when considering whether to attempt to argue a payment claim on the basis of a minor technicality or ambiguity.

If you or someone you know wants more information or needs help or advice in relation to NSW’s security of payment legislation (or any other state’s or territory’s equivalent), please contact us on (02) 9248 3450 or email info@bradburylegal.com.au.

ADR Processes

 

ADR Processes: What are they and how do they work?

 

In many construction contracts, it is common to have a clause that deals with the process the parties will go through if a dispute arises. These clauses attempt to provide an alternative dispute resolution (ADR) process to litigating over every dispute that arises. While there are some disputes that are suited to being litigated (such as where a specific legal remedy is needed, the subject matter involves the legal rights of the parties or the issues are legally complex), many can be resolved through an ADR processes. ADR processes, if effective, can reduce the time and cost of disputes for parties.

 

This article discusses the different types of ADR processes and Part II will address some of the common pitfalls of ADR clauses that render these clauses unenforceable.

 

Types of ADR processes:

 

When it comes to construction disputes, there are several standard types of ADR processes. These include:

 

  • Negotiations between senior executives or authorised representatives;
  • Mediation;
  • Arbitration; and
  • Expert determination and appraisal.

 

Negotiations

 

Negotiation between senior executives is the most simple and informal dispute resolution process. The senior executives or authorised representatives meet and discuss the dispute that has arisen. Using their best endeavours, the authorised representatives can talk about how the dispute may be resolved and attempt and find any potential compromises. While the discussions may not necessarily resolve the dispute, it gives the parties a chance to hear the other side and understand the issues faced by the other party. This can help narrow the issues that are in dispute between the parties, saving significant time and money if the dispute escalates to litigation.

 

Mediation

 

The next step in the ADR ladder is mediation. Mediation is slightly more formal than negotiations between the parties’ authorised or senior representatives. This is because mediation involves appointing a third party (the mediator) to meet with the parties and work to resolve the dispute. The mediator will discuss the positions and interests of each party and try to find common ground on which the parties can agree and tries to help facilitate a resolution of the dispute.

 

One of the biggest benefits of mediation is the fact that it is so flexible in the resolutions that can be generated in response to a dispute. For instance, parties can find creative or unorthodox solutions to their problems which would not be available if the dispute were to be litigated. At mediation, the parties have the control over the resolution of the dispute and can work together to create a solution that is potentially more appropriate than a court order.

Arbitration

 

Arbitration is a common dispute resolution process in the building industry. Between commercial parties, arbitration can be an effective alternative to court because it operates much like a Court. The Commercial Arbitration Act 2010 (NSW) sets out the various matters relating to domestic commercial arbitrations including the arbitrator’s powers and the appeal process. The decisions of arbitrators are binding and the resulting awards can be enforced by the Courts.

 

Arbitrations can sometimes be as expensive and time consuming as litigation. This is because of several factors such as the cost of hiring an arbitrator and decisions are often appealed. However, some of the benefits of choosing arbitration include that it can be confidential and allows the parties to have more control over the rules and procedures that resolve the dispute. Subject to any overriding arbitration legislation or rules, the parties can essentially decide how they want the determination to run, how many arbitrators they want involved or any grounds of appeal.

 

Expert Determination

 

Another ADR process discussed in this article is expert determination. Expert determination can be binding, or non-binding (dependent on the rules of the particular expert agreement or contract that sends the parties in dispute into that forum). Unlike arbitration, there is no statutory framework for expert determination or appraisal. Therefore, it is the contract that will guide the expert and their decision. Using an expert to make a final and binding decision is useful, as the majority (if not all) building disputes will rely on expert evidence to determine issues such as program, defects or rectification costs.

 

Using non-binding expert determination can prevent or reduce the need for a court to consider these technical issues and can simplify the litigation process. A potential drawback for expert determination is that it can be very difficult to challenge. Provided the expert has understood the scope of their obligations and the issues they need to review, it often will not matter if the expert made a mistake, a gross over or under valuing or if irrelevant considerations were considered. As stated by the NSW Supreme Court in TX Australia Pty Limited v Broadcast Australia Pty Limited [2012], the fundamental question is whether the exercise performed by the expert in fact satisfies the terms of the contract.

 

It is not uncommon for a dispute resolution clause to have multiple different ADR processes available to the parties. For example, parties may be required to enter negotiations with each other and then must proceed to mediation or arbitration. Therefore, it is important to understand the aspects of each different ADR process so that you can choose the one most appropriate for your business. Each ADR process has its benefits and its drawbacks and will be more effective for certain types of disputes. In the Part II of this article, we will look at dome of the common pitfalls of ADR clauses. Particularly, how you ensure that the clause is enforceable, the key aspects of the ADR clause, and what are the common issues that arise when negotiating an ADR clause.

What’s in a name?: The Supreme Court Reviews ambiguity in SoPA Payment Claims

Those who are familiar with the Building and Construction Industry Security of Payment Act 1999 (‘the Act’) will likely be aware that the provisions it contains are quite strict, and can leave parties out in the cold when they fail to comply with what are seemingly administrative oversights.

However, the overarching purpose of the Act is ultimately to keep money flowing through the construction system, aimed at ensuring those who perform building and construction works, or supply goods and services to construction projects are able to be paid.

The Supreme Court of New South Wales, in the recent decision of decision Modog Pty Ltd v ZS Constructions (Queenscliff) Pty Ltd [2019] NSWSC 1743 reminded parties of this fact when asked to turn its mind to issues of ambiguity in payment claims and whether a party could be allowed to have an adjudication determination quashed on the basis of technicalities.

The Facts

The facts of the case were reasonably clear and did not form a substantial component of the dispute between the parties. In September 2016, Modog Pty Ltd (‘Modog’) entered into a design and construct head contract with Wyndora 36 Pty Ltd (‘Wyndora’) for the development of senior living apartments at a property located along Wyndora Avenue in Freshwater. Modog then entered a sub-contract with ZS Constructions (Queenscliff) Pty Limited (ZS Queenscliff) for the demolition of the existing structure and the construction of the new seniors living complex, including apartments, basement parking and associated site works (‘the Sub-Contract’).

In March 2018, the Sub-contract was varied to engage ZS Queenscliff to provide Construction Management and procurement services, for which ZS Queenscliff would receive a project manager’s allowance, a contract administrator’s allowance and payments for subcontractors and suppliers to be made at the end of each month.

ZS Queenscliff was part of a wider group of entities, which also included ZS Constructions (Australia) Pty Ltd (‘ZS Australia’) and Zaarour Investments Pty Ltd had been engaged as the project manager for the project. Mr Christopher Zaarour was employed by ZS Queenscliff, was the director of ZS Constructions Pty Ltd and was the primary contact with Modog for the duration of the project.

The further sub-contracts on the project were administered by ZS Queenscliff, however invoices from sub-contractors had historically been issued to a mixture of Modog, Wyndora and ZS Australia, as opposed to ZS Queenscliff. During the course of the project, ZS Queenscliff and Modog adopted a progress payments process in which Mr Zaarour would, on behalf of ZS Queenscliff, prepare and email a payment summary sheet listing all amounts due for procurement and management services, as well as materials acquired, and work completed by trade contractors.

On 29 August 2019, Modog issued a Show Cause Notice to ZS Queenscliff and terminated the Sub-contract on 13 September 2019.

The Payment Claim and Adjudication

On 11 September 2019, ZS Queenscliff served a payment claim on Modog which was comprised of seven emails, from Mr Zaarour using an email signature from Zaarour Sleiman and containing a reference to ZS Australia in fine print at the bottom of the email.

The emails attached supporting invoices from suppliers, and followed the process adopted in earlier progress payments, where sub-contractors and suppliers had addressed their invoices to a mixture of the entities involved with the project, and not to ZS Queenscliff, who were issuing the payment claim.

The payment claim served on Modog was, as highlighted by the Court, unclear in the following respects:

  • It did not specifically assert that it was a progress payment claim under the Act;
  • It did not specify the reference date or refer to the clause within the contract upon which the progress payment was based;
  • It failed to ask Modog to pay ZS Queenscliff;
  • It did not include a total for the sum claimed, only determinable by a thorough review of the claims

Modog, in turn responded to the payment claim with payment schedules which certified the amount payable in respect of the Claim was nil.

The matter proceeded to an adjudication, where, on 23 October 2019, the adjudicator found in favour of ZS Queenscliff in the sum of $89,111.89 (GST incl.).

Modog challenged the decision of the adjudicator before the Supreme Court of Sydney, seeking orders that the Adjudication Determination of be deemed void, that the determination be quashed, and ancillary relief.

The Disputed Issues

At the hearing, Modog challenged the decision of the adjudicator on 3 primary grounds:

  • Whether the 11 September 2019 emails constituted a payment claim within the meaning of s13(1) of the Act;
  • If the emails did constitute a payment claim, whether the claim was sent by ZS Queenscliff as a person who was entitled to seek a determination for the purposes of s17 of the Act; and
  • Whether the Adjudicator has committed a jurisdictional error by allowing multiple payment claims in respect of a single reference date?

The Arguments, Decision and Reasoning

Issue 1: Was there a Payment Claim:

The argument advanced by Modog was effectively, ZS Queenscliff had not submitted a valid payment claim as they did not specifically demand payment from Modog (i.e.: did not say, Modog must pay ZS Queenscliff the sum of $X.). Modog relied on the fact that the invoices provided in support of the payment claim, were addressed to various entities, not ZS Queenscliff, and that ZS Queenscliff could not establish they were actually entitled to the money claimed for.

Modog argued that ZS Queenscliff had indicated invoices would be sent at a later time, which Modog was to pay as directed and that, pursuant to the Court’s decision in Quickway Constructions Pty Ltd v Electrical Energy Pty Ltd, ZS Queenscliff had not served a payment claim pursuant to clause 13(1) of the Act.

The counter argument raised by ZS Queenscliff relied upon the case of Icon Co NSW Pty Ltd v Australia Avenue Developments Pty Ltd [2018] to support their position that Modog had simply misunderstood the payment claim, and that this could not be a basis for quashing the adjudicator’s decision. ZS Queenscliff argued the fact that the invoices were addressed to other parties did not invalidate the payment claim as they were simply disbursements to be paid to suppliers.

Ultimately, the Court favoured the position raised by ZS Queenscliff, noting there is nothing within the Act that requires a payment claim to state the total of the sum claimed. The Court stated and that even if the invoices in support of the payment did require Modog to direct payment elsewhere, as long as ZS Queenscliff had an entitlement to the sum under the contract, this did not invalidate the payment claim itself.

Issue 2: Was the Payment Claim Sent by ZS Queenscliff?

Modog then raised the issue that, as the 11 September 2019 email enclosing the payment claim was sent by Mr. Zaarour, using an email signature that did not belong to ZS Queenscliff, and the only legal entity named in the email was ZS Australia, the payment claim had not been served by the appropriate entity for the purposes of s17 of the Act.

The counter argument raised by ZS Queenscliff was that these errors were irrelevant in light of the fact that the previous correspondence between the parties had been exchanged in much the same way, including when detailing the terms of the caries contract agreements, and the point was not taken at the contract negotiation stage.

The Court ultimately agreed again with ZS Queenscliff, making the point that not was not actually disputed that ZS Queenscliff was entitled to make the payment claim and made the determination that the email payment claim had simply been sent by Mr Zaarrour in his capacity as the project manager, on behalf of ZS Queenscliff.

Issue 3: Was there an issue with multiple emails being used to comprise the payment claim?

Finally, Modog sought to raise the point that multiple invoices had been served on them in the emails from ZS Queenscliff and that it was not open for ZS Queenscliff to seek to have all invoices adjudicated.

Relying on the decision of the court in Rail Corporations of NSW v Nebax Constructions [2012] NSWSC6, this point ultimately failed as well, on the basis that, when viewed in the context of the previous conduct between the parties, and the nature of the invoices supplied, Modog had been more accurately provided with one payment claim, and a number of invoices in support of the claim.

What does this decision mean?

This decision serves as a timely reminder to parties that the Building and Construction Industry Security of Payment Act 1999 (‘the Act’) is intended to allow money to flow through to sub-contractors. Parties should be mindful of this purpose when considering whether to attempt to argue a payment claim on the basis of a minor technicality or ambiguity.

If you or someone you know wants more information or needs help or advice in relation to NSW’s security of payment legislation (or any other state’s or territory’s equivalent), please contact us on (02) 9248 3450 or email info@bradburylegal.com.au.

The benefits of mediation in a commercial dispute

The popular image of a lawyer is a person keen on prolonging an expensive court action.

More often the opposite is true. Lawyers know that court cases are expensive and that clients are fearful that legal costs could escalate to an intolerable level. They are also all too aware of how long and unpredictable litigation can end up becoming. Lawyers interested in preserving long-standing relationships with their clients will often recommend alternative dispute resolution options – mediation being one.

Mediation allows parties to remain in control of their own disputes and outcome while facilitating parties to tell their side of the story to the other party and the mediator.

What exactly is mediation?

Mediation is one form of alternative dispute resolution with others including Early Neutral Evaluation, expert determination and arbitration.

In essence mediation is an informal conflict resolution process brought before an independent, neutral third party. Mediation gives the parties the opportunity to discuss their issues, clear up misunderstandings, and find areas of agreement in a way that would never be possible in a court case.

Mediation is often voluntary. Typically the mediator has no authority to make a binding decision unless both parties agree to give the mediator that power which is dealt with in advance of the mediation commencing.

When parties should consider mediation

In practical terms mediation is likely to be quicker and more cost-effective than the more formal processes of arbitration or litigation (in court). Mediation should be considered as early as possible after a dispute has arisen. It is particularly appropriate where a dispute involves complex issues and/or multiple parties.

In addition, mediation can be implemented prior to, or in conjunction with, other forms of dispute resolution such as arbitration or court proceedings.

In circumstances where privacy and confidentiality are important, mediation enables parties to preserve these rights without public disclosure. This often leads to more satisfactory outcomes for both parties.

Advantages of mediation

Some of the many advantages to mediation are as follows:

You get to decide: The responsibility and authority for coming to an agreement remain with the people who have the conflict. The dispute is viewed as a problem to be solved. The mediator doesn’t make the decisions, and you don’t need to “take your chances” in the courtroom. In doing this however, naturally you need to understand your legal rights so that you can make decisions that are in your own best interests.

The focus is on needs and interests: Mediation examines the underlying causes of the problem and looks at what solutions best suit your unique needs and to satisfy your interests.

For a continuing relationship: Colleagues, business partners, and family members have to continue to deal with each other co-operatively. Going to court can divide people and increase hostility. Mediation looks to the future. It helps end the problem, not the relationship.

Mediation deals with feelings: Each person is encouraged to tell their own story in their own way. Discussing both legal and personal issues can help you develop a new understanding of yourself and the other person. You are encouraged to see things from the other person’s perspective.

Higher satisfaction: Participants in mediation report higher satisfaction rates than people who go to court. Because of their active involvement, they have a higher commitment to upholding the settlement than people who have a judge decide for them. Mediations end in agreement about 80 percent of the time and have high rates of compliance.

Informality: Mediation can be a less intimidating process than going to court. Since there are no strict rules of procedure, this flexibility allows the people involved to find the best path to agreement.  Although it is normal for any dispute resolution to be taxing emotionally, mediation is a process that is much less confronting and is conducted in a much more comfortable environment than litigation.

Faster than going to court: Years may pass before a case comes to trial, while a mediated agreement may be obtained in a couple of hours or in sessions over a few weeks.

Lower cost: The court process is expensive, and costs can exceed benefits. It may be more important to apply that money to solving the problem, to repairing damages, or to paying someone back. Mediation services are available at low cost for some types of cases. If you can’t agree, other legal options are still possible. Even a partial settlement can lessen later litigation fees.

Privacy: Unlike most court cases, which are matters of public record, most mediations are confidential.

Where mediation is not the solution

With mediation a resolution is not guaranteed. There is the potential that parties may invest time and money in trying to resolve a dispute out of court, and still end up having to go to court. Ultimately it is a call that should be made in consultation with an experienced lawyer.

Mediation should not be a solution in circumstances where it is not appropriate. Where a court remedy is necessary such as an injunction or specific and urgent court orders, mediation is not helpful.

It must also be remembered that the mediator has no power to impose a binding decision on the parties. Therefore, even after the mediation the matter may be unresolved and you may still need to go to court. This is where the selection of the mediator requires careful consideration by all parties.

Fundamentally, mediation rarely produces a satisfactory resolution unless both parties to a dispute are committed to a resolution by this way. If one party does not cooperate or engage with the processes, mediation will be fruitless.

Conclusion

Mediation is an alternative to financially and emotionally costly and time-consuming processes such as using the court system. It is suitable for people who are willing to communicate with the other party and attempt to better understand and settle their dispute with the help of a trained third party.

To find out more call us on +612 9248 3450 or email info@bradburylegal.com.au.

Different options for resolving building disputes

A building dispute can have serious implications for all parties involved, the most obvious being delays to the construction project and the resulting financial loss.

A dispute may arise from disagreements over the interpretation of a contract term, incomplete or defective works, variations to the scope of works, or charges for prime cost items and provisional sums.

Bringing a building dispute matter before a court or tribunal can exacerbate the issues between the parties, delay the project further, incur additional costs and cause even more damage to the parties’ strained relationship. It is almost always beneficial to settle a building dispute through alternative dispute resolution (ADR).

ADR involves retaining an impartial third party to assist in reaching an early settlement of the matter. In fact, most jurisdictions require that parties to a building dispute make genuine attempts to settle the matter before proceeding to a tribunal or court.

Construction contracts often contain ADR clauses that specify the approach to be used if a dispute arises. The ADR method may be facilitative, advisory or determinative.

When preparing or entering a construction contract, it is important to understand the different ADR approaches and their implications, and to choose the type most suited to the circumstances. If there is no ADR clause, the parties may agree to use a particular method. The following is a summary of each.

Facilitative

A building dispute may be resolved through mediation which involves a neutral person meeting face to face with the parties to assist them in narrowing the disputed issues, exploring options and reaching a solution.

Mediation is informal and confidential, and the mediator does not provide legal advice nor does he or she determine the matter. The parties should be willing to negotiate in good faith and make genuine attempts to resolve the dispute.

The parties meet in a “without prejudice” environment and the mediator coaches the parties through the issues and encourages them to engage in meaningful negotiations.

Mediation allows the parties to reach an early settlement that may be more flexible than one imposed by a court or tribunal and may assist in preserving the parties’ commercial relationship allowing them to continue working throughout the project and beyond.

The construction contract will usually specify who may be appointed as a mediator and stipulate who is responsible for the costs of the mediation – this is often shared equally between the parties.

Advisory

Advisory ADR processes may include conciliation, expert appraisal and case appraisal. Each involve the appointment of a third party to consider the available material and provide advice regarding the facts and appropriate law and how the matter may be settled.

Early Neutral Evaluation was first used in the United States in response to a critical backlog of cases within the courts system and generally falls within the category of case appraisal. An evaluator with knowledge of the law is appointed and considers the parties’ respective arguments and evidence. The evaluator may be a dispute resolution practitioner or judicial officer. They make a non-binding evaluation of the strengths and weaknesses of each side, the likely liability and an estimate of damages.

In other words, the parties are provided an expert opinion, from an experienced and respected neutral party, regarding the likely outcome if the matter was to go to a court or tribunal. The evaluation is confidential, and the appraisal provided generally encourages settlement without the delay, costs and formalities associated with a court or tribunal hearing.

Senior Executive Appraisal, also known as a mini-trial, involves a panel of senior experts joining an independent neutral third party to consider and evaluate the dispute. The parties present their own evidence and the panel convene to attempt to settle the matter. The power conferred on the panel and independent third-party is predetermined by agreement.

Determinative

An independent expert with appropriate technical knowledge is appointed by the parties to determine the dispute. The determination is generally made on the respective parties’ written submissions, statements and evidence and the expert may conduct his or her own investigations before determining an award. Oral evidence does not usually form part of the process.

The contract generally sets out the process governing this method of ADR, including who the expert should be, how the expert is appointed, the relevant timeframes, the binding nature of the decision and how costs are to be paid.

If the contract provides for the determination to be binding and a party refuses to comply with the decision, then the other party will generally need to rely on the contract’s provisions to enforce the decision through the court.

When ADR is unsuccessful

Not all building disputes may be successfully negotiated.

If resolution is impossible or impractical, either party may make the appropriate application to their state or territory Administrative Tribunal or court. The matter will proceed according to the type of construction project, the value of the claim, and the parties to the dispute. Tribunals and courts are formal jurisdictions and have strict processes and timeframes.

Conclusion

Unresolved building disputes can escalate quickly depleting valuable time and resources of the parties involved. Utilising ADR to resolve a dispute can be time efficient, cost effective and assist in preserving the relationship between the parties.

Determining which ADR method is appropriate will depend on the facts and circumstances of each case. In all matters however, the parties should be willing to listen and make genuine efforts to negotiate and resolve the issues.

If you or someone you know wants more information or needs help or advice, please contact us on +61 2 9248 3450 or email info@bradburylegal.com.au.